Official text of 3452.242-71
As prescribed in 3442.7002, insert the following clause in all solicitations and contracts other than purchase orders:
Notice to the Government of Delays (MAR 2011)
The contractor shall notify the contracting officer of any actual or potential situation, including but not limited to labor disputes, that delays or threatens to delay the timely performance of work under this contract. The contractor shall immediately give written notice thereof, including all relevant information.
(End of clause)
Where it's prescribed
As prescribed in 3442.7002, insert the following clause in all solicitations and contracts other than purchase orders:
Verifying this text
The text above is reproduced verbatim from GSA's published source files for the Education supplement. The controlling version is the one in the Code of Federal Regulations: 3452.242-71 on eCFR.